Terms & Conditions

Agreement to Terms

By accessing and using the Direct Siding Idaho website or requesting our services, you agree to be bound by these Terms and Conditions. If you do not agree to these terms, please do not use our website or services.

Services Provided

Direct Siding Idaho provides professional siding installation, replacement, repair, and maintenance services for residential and commercial properties in Boise, Coeur d'Alene, and surrounding areas in Idaho.

All services are subject to a written contract or work order that specifies the scope of work, materials, timeline, and pricing. Services may not commence until a signed agreement is in place.

Estimates and Quotes

Free estimates are provided for informational purposes only and are not binding until a formal contract is executed. Estimates are valid for 30 days from the date of issue unless otherwise specified.

Actual costs may vary based on unforeseen conditions discovered during the project, changes in material costs, or modifications to the scope of work requested by the customer.

Payment Terms

Payment terms will be specified in your service contract. Typically:

• A deposit may be required before work begins
• Progress payments may be due at specified milestones
• Final payment is due upon completion and customer approval
• Late payments may be subject to additional fees

We accept cash, checks, credit cards, and may offer financing options through approved partners.

Warranties

Direct Siding Idaho provides workmanship warranties on all installations. Specific warranty terms will be detailed in your service contract. Materials are covered by manufacturer warranties, which vary by product.

Warranties may be void if damage occurs due to improper maintenance, unauthorized modifications, acts of nature, or other factors beyond our control.

Project Timeline

Project timelines are estimates and may be affected by weather conditions, material availability, unforeseen site conditions, or other factors beyond our control. We will make reasonable efforts to complete projects on schedule and will communicate any delays promptly.

Cancellation Policy

Customers may cancel services according to the terms specified in their service contract. Cancellation fees may apply to cover costs already incurred, including materials ordered, labor scheduled, and administrative expenses.

Limitation of Liability

Direct Siding Idaho's liability is limited to the cost of the services provided. We shall not be liable for indirect, incidental, consequential, or punitive damages arising from our services or any delays in performance.

We maintain appropriate insurance coverage and will work to resolve any issues that arise during or after project completion.

Intellectual Property

All content on this website, including text, graphics, logos, images, and software, is the property of Direct Siding Idaho and is protected by copyright and other intellectual property laws. You may not reproduce, distribute, or create derivative works from this content without our express written permission.

Changes to Terms

We reserve the right to modify these Terms and Conditions at any time. Changes will be effective immediately upon posting to this website. Your continued use of the website or services after changes are posted constitutes your acceptance of the modified terms.

Governing Law

These Terms and Conditions shall be governed by and construed in accordance with the laws of the State of Idaho, without regard to its conflict of law provisions. Any disputes arising from these terms shall be resolved in the courts of Idaho.

Contact Information

If you have any questions about these Terms and Conditions, please contact us: